Agreement between Owner and Contractor




Agreement between Owner and Contractor :





This Agreement between Owner and Contractor is hereby made and entered into this _____ day of __________, 19___, by and between __________, hereafter called Owner, and __________, hereafter called Contractor.


The said parties, for the considerations hereinafter mentioned, hereby agree to the following.


1. The Contractor agrees to provide all of the material and laborrequired to perform the following work for: [Describe work to bePerformed] as shown by the drawing(s) and described in the specifications prepared by __________ and provided by the Owner, which are identified by the signatures of the parties to this agreement and which form a part of this agreement.


2. The Owner hereby agrees to pay the Contractor, for the aforesaid materials and labor, the sum of __________, in the following manner: [Describe Method and Timing of Payment]


3. The Contractor agrees that the various portions of the above described work shall be completed on or before the following dates : [Insert Dates] and the entire above-described work shall be completed no later than the _____ day of __________, 19____.


4. The Contractor agrees to provide and pay for all materials, tools and equipment required for the prosecution and timely completion of the work. Unless otherwise specified, all materials shall be new and of good quality.


5. In the prosecution of the work, the Contractor shall employ asufficient number of workers skilled in their trades to suitably perform the work.


6. All changes and deviations in the work ordered by the Owner must be in writing, the contract sum being increased or decreased accordingly by the Contractor. Any claims for increases in the cost of the work must be presented by the Contractor to the Owner in writing, and written approval of the Owner shall be obtained by the Contractor before proceeding with the ordered change or revision.


7. The Owner, Owner's representative and public authorities shall at all times have access to the work.


8. The Contractor agrees to re-execute any work which does not conform to the drawings and specifications, warrants the work performed and agrees to remedy any defects resulting, from faulty materials or workmanship which shall become evident during a period of one year after completion of the work.


9. The Owner agrees to maintain full insurance on the above-described work during the progress of the work, in his own name and that of the Contractor.


10. In the event the Contractor is delayed in the prosecution of the work by acts of God, fire, flood or any other unavoidable casualties or by labor strikes, late delivery of materials or by neglect of the Owner the time for completion of the work shall be extended for the same period as the delay occasioned by any of the aforementioned causes.


11. In the event the work is delayed due to neglect of the Contractor, the Contractor agrees to pay the Owner the sum of __________ per __________ as liquidated damages until such time as the work is completed.


12. The Contractor agrees to obtain insurance to protect himself against claims for property damage, bodily injury or death due to his performance of this agreement.


13. Neither the Owner nor Contractor shall have the right to assign any rights or interest occurring under this agreement without the written consent of the other nor shall the Contractor assign any sums due or to become due, to him under the provisions of this agreement.


14. This agreement shall be interpreted under laws of the State of __________.


15. Attorney's fees and court costs shall be paid by the defendant in the event that judgment must be and is obtained to enforce this agreement or any breach thereof.


IN WITNESS WHEREOF the parties hereto set their hands and seals the day and year written above.


By :


By :


This is an Agreement between Owner and Contractor.


This is an Agreement between Owner and Contractor.





From
Agreement between Owner and Contractor
to HOME PAGE


Letter Asking A Donation
Letter Asking A Favor
Letter Asking for More Details
Letter Asking for Donations
Letter Denying of Dealership
Letter for Change of Address
Letter for Distributorship
Letter for Employment
Letter for Hotel Reservation
Letter for Letter of Credit
Letter for Line of Credit
Letter for Product Launch
Letter for Promotion
Letter for Retirement Congrats
Letter for Scholarship
Letter for Settlement of Bill
Letter for Tender
Letter for Testimonial
Letter of Agreement
Letter of Assurance
Letter of Credit
Letter of Enquiry
Letter of Order
Letter of Persuasion
Letter of Sympathy
Letter Offering Discount
Letter Related to Advertisement
Letter Related to Despatch
Letter Related to Training
Letter to A Foreign Buyer
Letter to Pen-Friend
Letter to Police
Letter with Order
Letter with Quotation
Letter Writing
Letters about Company Shares
Letters by Clubs and Societies
Letters by Landlords & Tenants
Letters for Appointment of Dealers
Letters for Business Relations
Letters for Buying and Selling
Letters for Credit & Collection
Letters for Foreign Travel
Letters for Lease & Tenancy
Letters for Loan & Borrowing
Letters for Transfer & Assignment
Letters for Insurance
Letters Noting Discrepancy
Letters of Condolence & Sorrow
Letters of Regret
Letters Regarding Maintenance
Letters Regarding Payment
Letters Related to Employees
Letters to Local Corporation
Letters to Postal Authorities
Letters to The Editor
Letters Used in Real Estate
Letters With Postal Department
Letters With Railways Authorities


About This Site :

About Us
Contact Us
Link Partners
Privacy Policy